Loading...
HomeMy WebLinkAboutR-2022-039 Awarding Bid for Additions & Renovation Riverside Public Safety Building to Crossland Construction Company, Inc. RESOLUTION NO. R-2022-039 A RESOLUTION AWARDING THE BID FOR ADDITIONS & RENOVATION TO THE RIVERSIDE PUBLIC SAFETY BUILDING AND APPROVING THE AGREEMENT BETWEEN THE CITY AND CROSSLAND CONSTRUCTION COMPANY, INC. FOR CONSTRUCTION OF SUCH PROJECT WHEREAS, the City issued a request for bids for the construction of improvements for the Riverside Public Safety Building (Project No. 537-086) ("Project"); and WHEREAS, the City received eight (8) responses to its request for bid and the proposal submitted by Crossland Construction Company, Inc. ("Crossland") in the amount of$4,717,000.00 has been evaluated by the City and WSKF Architects and recommended as the most advantageous proposal for performance of the project; and WHEREAS, the Board of Aldermen find it is in the best interest of the City to enter into a contract with Crossland to perform the Project; NOW, THEREFORE, BE IT RESOLVED BY THE BOARD OF ALDERMEN OF THE CITY OF RIVERSIDE, MISSOURI AS FOLLOWS: THAT the proposal of Crossland for the construction of the Project in the amount of $4,717,000.00 is hereby accepted and approved; and FURTHER THAT an agreement by and between the City of Riverside and Crossland in substantially the same form as attached hereto in Exhibit "1" and incorporated herein by reference is hereby authorized and approved; and FURTHER THAT the project is subject to the requirements of Section 292.675 RSMo, which requires all contractors or subcontractors doing work on the project to provide, and require its on-site employees to complete, a ten (10) hour course in construction safety and health approved by the Occupational Safety and Health Administration (OSHA) or a similar program approved by the Missouri Department of Labor and Industrial Relations which is at least as stringent as an approved OSHA program. Such training must be completed within sixty (60) days of the date work on the Project commences. On-site employees found on the worksite without documentation of the required training shall have twenty (20) days to produce such documentation; and FURTHER THAT the Mayor, City Administrator, City Attorney, and Finance Director are hereby authorized to execute all documents and agreements necessary or incidental to carry out the terms and conditions of such bid award and the City Clerk is authorized to attest thereto. PASSED AND ADOPTED by the Board of Aldermen of the City of Riverside Missouri the 17th day of May 2022. ath een L. Rose, Mayo ATTE T: Robin Kincaid, ity Clerk EXHIBIT "1" 1) Standard Form of Agreement Between Owner and Contractor Exhibit A, Insurance and Bonds 2) General Conditions of the Contract for Construction Exhibit B, Drawings Exhibit C, Specifications 4 AIA Document A101® - 2017 Standard Form of Agreement Between Owner and Contractor where the basis of payment is a Stipulated Sum AGREEMENT made as of the Sixteenth day of May in the year Two Thousand Twenty Two (In words, indicate day, month and year.) ADDITIONS AND DELETIONS: The author of this document has BETWEEN the Owner: added information needed for its (Name, legal status, address and other information) completion.The author may also have revised the text of the original City of Riverside,Missouri AIA standard form.An Additions and 2950 NW Vivion Road Deletions Report that notes added Riverside,MO information as well as revisions to the standard form text is available from WSKF Project No.21010 the author and should be reviewed.A vertical line in the left margin of this and the Contractor: document indicates where the author (Name, legal status, address and other information) has added necessary information and where the author has added to or Crossland Construction Company,Inc. deleted from the original AIA text. 833 S.East Avenue This document has important legal Columbus,KS 66725 consequences.Consultation with an attorney is encouraged with respect for the following Project: to its completion or modification. (Name, location and detailed description) The parties should complete A1018-2017,Exhibit A,Insurance Additions&Renovation and Bonds,contemporaneously with Riverside Public Safety this Agreement.AIA Document 2990 NW Vivion Road A201®-2017,General Conditions of Riverside,Missouri the Contract for Construction,is adopted in this document by The Architect: reference.Do not use with other (Name, legal status, address and other information) general conditions unless this document is modified. WSKF,Inc. 110 Armour Road North Kansas City,MO 64116 The Owner and Contractor agree as follows. Init. AIA Document A1010—2017.Copyright©1915,1918,1925,1937,1951,1958,1961,1963,1967,1974,1977,1987,1991,1997,2007 and 2017 by The American Institute of Architects.All rights reserved.The"American Institute of Architects,""AIA,"the AIA Logo,"A101,"and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA software at 09:36:29 ET on 05/12/2022 under Order No.2114242632 which expires on 10/19/2022,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail copyright@aia.org. User Notes: (1429423941) TABLE OF ARTICLES 1 THE CONTRACT DOCUMENTS 2 THE WORK OF THIS CONTRACT 3 DATE OF COMMENCEMENT AND SUBSTANTIAL COMPLETION 4 CONTRACT SUM 5 PAYMENTS 6 DISPUTE RESOLUTION 7 TERMINATION OR SUSPENSION 8 MISCELLANEOUS PROVISIONS 9 ENUMERATION OF CONTRACT DOCUMENTS EXHIBIT A INSURANCE AND BONDS ARTICLE 1 THE CONTRACT DOCUMENTS The Contract Documents consist of this Agreement,Conditions of the Contract(General, Supplementary,and other Conditions),Drawings,Specifications,Addenda issued prior to execution of this Agreement,other documents listed in this Agreement,and Modifications issued after execution of this Agreement,all of which form the Contract,and are as fully a part of the Contract as if attached to this Agreement or repeated herein.The Contract represents the entire and integrated agreement between the parties hereto and supersedes prior negotiations,representations,or agreements, either written or oral.An enumeration of the Contract Documents,other than a Modification,appears in Article 9. ARTICLE 2 THE WORK OF THIS CONTRACT The Contractor shall fully execute the Work described in the Contract Documents,except as specifically indicated in the Contract Documents to be the responsibility of others. ARTICLE 3 DATE OF COMMENCEMENT AND SUBSTANTIAL COMPLETION § 3.1 The date of commencement of the Work shall be: (Check one of the following boxes.) [ ] The date of this Agreement. [ X ] A date set forth in a notice to proceed issued by the Owner. [ ] Established as follows: (Insert a date or a means to determine the date of commencement of the Work.) If a date of commencement of the Work is not selected,then the date of commencement shall be the date of this Agreement. § 3.2 The Contract Time shall be measured from the date of commencement of the Work. § 3.3 Substantial Completion § 3.3.1 Subject to adjustments of the Contract Time as provided in the Contract Documents,the Contractor shall achieve Substantial Completion of the entire Work: (Check one of the following boxes and complete the necessary information.) Init. AIA Document A101e—2017.Copyright e 1915,1918,1925,1937,1951,1958,1961,1963,1967,1974,1977,1987,1991,1997,2007 and 2017 by The American Institute of Architects.All rights reserved.The"American Institute of Architects,""AIA,"the AIA Logo,"A101,"and"AIA Contract Documents"are 2 registered trademarks and may not be used without permission.This document was produced by AIA software at 09:36:29 ET on 05/12/2022 under Order No.2114242632 which expires on 10/19/2022,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail copyright@aia.org. User Notes: (1429423941) [ X ] Not later than two hundred forty(240)calendar days from the date of Notice to Proceed. [ ] By the following date: § 3.3.2 Subject to adjustments of the Contract Time as provided in the Contract Documents,if portions of the Work are to be completed prior to Substantial Completion of the entire Work,the Contractor shall achieve Substantial Completion of such portions by the following dates: Portion of Work Substantial Completion Date All Work. Date shall be 240 calendar days from the Notice to Proceed. § 3.3.3 If the Contractor fails to achieve Substantial Completion as provided in this Section 3.3,liquidated damages,if any,shall be assessed as set forth in Section 4.5. ARTICLE 4 CONTRACT SUM § 4.1 The Owner shall pay the Contractor the Contract Sum in current funds for the Contractor's performance of the Contract.The Contract Sum shall be Four Million Seven Hundred and Seventeen Thousand Dollars and 00/100's ($4,717,000.00),subject to additions and deductions as provided in the Contract Documents. § 4.2 Alternates § 4.2.1 Alternates,if any,included in the Contract Sum: Item Price § 4.2.2 Subject to the conditions noted below,the following alternates may be accepted by the Owner following execution of this Agreement.Upon acceptance,the Owner shall issue a Modification to this Agreement. (Insert below each alternate and the conditions that must be met for the Owner to accept the alternate.) Item Price Conditions for Acceptance N/A § 4.3 Allowances,if any,included in the Contract Sum: (Identify each allowance.) Item Price Testing&Inspections Allowance $15,000.00 § 4.4 Unit prices,if any: (Identify the item and state the unit price and quantity limitations, if any, to which the unit price will be applicable.) Item Units and Limitations Price per Unit($0.00) #1 Unsatisfactory Soil Cubic Yard $72.00 #2 Trench Rock Cubic Yard $165.00 § 4.5 Liquidated damages,if any: (Insert terms and conditions for liquidated damages, if any.) § 4.6 Other: (Insert provisions for bonus or other incentives, if any, that might result in a change to the Contract Sum.) N/A Init. AIA Document A101®—2017.Copyright©1915,1918,1925,1937,1951,1958,1961,1963,1967,1974,1977,1987,1991,1997,2007 and 2017 by The American Institute of Architects.All rights reserved.The"American Institute of Architects,""AIA,"the AIA Logo,"A101,"and"AIA Contract Documents"are 3 registered trademarks and may not be used without permission.This document was produced by AIA software at 09:36:29 ET on 05/12/2022 under Order No.2114242632 which expires on 10/19/2022,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail copyright@aia.org. User Notes: (1429423941) ARTICLE 5 PAYMENTS § 5.1 Progress Payments § 5.1.1 Based upon Applications for Payment submitted to the Architect by the Contractor and Certificates for Payment issued by the Architect,the Owner shall make progress payments on account of the Contract Sum to the Contractor as provided below and elsewhere in the Contract Documents. § 5.1.2 The period covered by each Application for Payment shall be one calendar month ending on the last day of the month,or as follows: (Paragraphs deleted) § 5.1.4 Each Application for Payment shall be based on the most recent schedule of values submitted by the Contractor in accordance with the Contract Documents.The schedule of values shall allocate the entire Contract Sum among the various portions of the Work.The schedule of values shall be prepared in such form,and supported by such data to substantiate its accuracy,as the Architect may require.This schedule of values shall be used as a basis for reviewing the Contractor's Applications for Payment. § 5.1.5 Applications for Payment shall show the percentage of completion of each portion of the Work as of the end of the period covered by the Application for Payment. § 5.1.6 In accordance with AIA Document A201Tm-2017,General Conditions of the Contract for Construction,and subject to other provisions of the Contract Documents,the amount of each progress payment shall be computed as follows: § 5.1.6.1 The amount of each progress payment shall first include: .1 That portion of the Contract Sum properly allocable to completed Work; .2 That portion of the Contract Sum properly allocable to materials and equipment delivered and suitably stored at the site for subsequent incorporation in the completed construction,or,if approved in advance by the Owner,suitably stored off the site at a location agreed upon in writing;and .3 That portion of Construction Change Directives that the Architect determines,in the Architect's professional judgment,to be reasonably justified. § 5.1.6.2 The amount of each progress payment shall then be reduced by: .1 The aggregate of any amounts previously paid by the Owner; .2 The amount,if any,for Work that remains uncorrected and for which the Architect has previously withheld a Certificate for Payment as provided in Article 9 of AIA Document A201-2017; .3 Any amount for which the Contractor does not intend to pay a Subcontractor or material supplier, unless the Work has been performed by others the Contractor intends to pay; .4 For Work performed or defects discovered since the last payment application,any amount for which the Architect may withhold payment,or nullify a Certificate of Payment in whole or in part,as provided in Article 9 of AIA Document A201-2017;and .5 Retainage withheld pursuant to Section 5.1.7. § 5.1.7 Retainage § 5.1.7.1 For each progress payment made prior to Substantial Completion of the Work,the Owner may withhold the following amount,as retainage,from the payment otherwise due: (Insert a percentage or amount to be withheld as retainage from each Application for Payment. The amount of retainage may be limited by governing law.) Refer to A201 General Conditions; Item 9.3.4. § 5.1.7.1.1 The following items are not subject to retainage: (Insert any items not subject to the withholding of retainage,such as general conditions, insurance, etc.) Insurance,Performance and Payment Bonds,General Conditions. Init. AIA Document A101•—2017.Copyright 01915,1918,1925,1937,1951,1958,1961,1963,1967,1974,1977,1987,1991,1997,2007 and 2017 by The American Institute of Architects.All rights reserved.The"American Institute of Architects,""AIA,"the AIA Logo,"A101,"and"AIA Contract Documents"are 4 registered trademarks and may not be used without permission.This document was produced by AIA software at 09:36:29 ET on 05/12/2022 under Order No.2114242632 which expires on 10/19/2022,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail copyright@aia.org. User Notes: (1429423941) § 5.1.7.2 Reduction or limitation of retainage,if any,shall be as follows: (If the retainage established in Section 5.1.7.1 is to be modified prior to Substantial Completion of the entire Work, including modifications for Substantial Completion of portions of the Work as provided in Section 3.3.2, insert provisions for such modifications.) Refer to A201 General Conditions; Item 9.3.4. § 5.1.7.3 Except as set forth in this Section 5.1.7.3,upon Substantial Completion of the Work,the Contractor may submit an Application for Payment that includes the retainage withheld from prior Applications for Payment pursuant to this Section 5.1.7.The Application for Payment submitted at Substantial Completion shall not include retainage as follows: (Insert any other conditions for release of retainage upon Substantial Completion.) If the work is found to be substantially non-compliant with the contract documents at the time of Substantial Completion,assessment of retainage amount shall be determined based on such non-compliance. § 5.1.8 If final completion of the Work is materially delayed through no fault of the Contractor,the Owner shall pay the Contractor any additional amounts in accordance with Article 9 of AIA Document A201-2017. § 5.1.9 Except with the Owner's prior approval,the Contractor shall not make advance payments to suppliers for materials or equipment which have not been delivered and stored at the site. § 5.2 Final Payment § 5.2.1 Final payment,constituting the entire unpaid balance of the Contract Sum,shall be made by the Owner to the Contractor when .1 the Contractor has fully performed the Contract except for the Contractor's responsibility to correct Work as provided in Article 12 of AIA Document A201-2017,and to satisfy other requirements,if any, which extend beyond final payment;and .2 a final Certificate for Payment has been issued by the Architect. § 5.2.2 The Owner's final payment to the Contractor shall be made no later than 30 days after the issuance of the Architect's final Certificate for Payment,or as follows: Refer to A201 General Conditions;Item 9.3. § 5.3 Interest Payments due and unpaid under the Contract shall bear interest from the date payment is due at the rate stated below, or in the absence thereof,at the legal rate prevailing from time to time at the place where the Project is located. (Insert rate of interest agreed upon, if any.) Eight Percent(8%) ARTICLE 6 DISPUTE RESOLUTION § 6.1 Initial Decision Maker The Architect will serve as the Initial Decision Maker pursuant to Article 15 of AIA Document A201-2017,unless the parties appoint below another individual,not a party to this Agreement,to serve as the Initial Decision Maker. (If the parties mutually agree, insert the name,address and other contact information of the Initial Decision Maker, if other than the Architect.) Rick Kuhl WSKF, Inc 110 Armour Road North Kansas City,MO 64116 In it. AIA Document A101®—2017.Copyright©1915,1918,1925,1937,1951,1958,1961,1963,1967,1974,1977,1987,1991,1997,2007 and 2017 by The American Institute of Architects.All rights reserved.The"American Institute of Architects,""AIA,"the AIA Logo,"A101,"and"AIA Contract Documents"are 5 registered trademarks and may not be used without permission.This document was produced by AIA software at 09:36:29 ET on 05/12/2022 under Order No.2114242632 which expires on 10/19/2022,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail copyright@aia.org. User Notes: (1429423941) § 6.2 Binding Dispute Resolution For any Claim subject to,but not resolved by,mediation pursuant to Article 15 of AIA Document A201-2017,the method of binding dispute resolution shall be as follows: (Check the appropriate box.) [ ] Arbitration pursuant to Section 15.4 of AIA Document A201-2017 [ X ] Litigation in a court of competent jurisdiction [ ] Other(Specify) If the Owner and Contractor do not select a method of binding dispute resolution,or do not subsequently agree in writing to a binding dispute resolution method other than litigation,Claims will be resolved by litigation in a court of competent jurisdiction. ARTICLE 7 TERMINATION OR SUSPENSION § 7.1 The Contract may be terminated by the Owner or the Contractor as provided in Article 14 of AIA Document A201-2017. (Paragraphs deleted) § 7.2 The Work may be suspended by the Owner as provided in Article 14 of AIA Document A201-2017. ARTICLE 8 MISCELLANEOUS PROVISIONS § 8.1 Where reference is made in this Agreement to a provision of AIA Document A201-2017 or another Contract Document,the reference refers to that provision as amended or supplemented by other provisions of the Contract Documents. § 8.2 The Owner's representative: (Name, address, email address, and other information) Mr.Travis Hoover,City Engineer City of Riverside,Missouri 2950 NW Vivion Road Riverside,Missouri § 8.3 The Contractor's representative: (Name, address, email address, and other information) Ivan Crossland Jr. Crossland Construction Company,Inc. 833 S. East Avenue Columbus,KS 66725 § 8.4 Neither the Owner's nor the Contractor's representative shall be changed without ten days'prior notice to the other party. § 8.5 Insurance and Bonds § 8.5.1 The Owner and the Contractor shall purchase and maintain insurance as set forth in AIA Document A101T"_2017,Standard Form of Agreement Between Owner and Contractor where the basis of payment is a Stipulated Sum,Exhibit A, Insurance and Bonds,and elsewhere in the Contract Documents. § 8.5.2 The Contractor shall provide bonds as set forth in AIA Document A 101 TM-2017 Exhibit A,and elsewhere in the Contract Documents. (Paragraphs deleted) Init. AIA Document A101®—2017.Copyright®1915,1918,1925,1937,1951,1958,1961,1963,1967,1974,1977,1987,1991,1997,2007 and 2017 by The American Institute of Architects.All rights reserved.The"American Institute of Architects,""AIA,"the AIA Logo,"A101,"and"AIA Contract Documents"are 6 registered trademarks and may not be used without permission.This document was produced by AIA software at 09:36:29 ET on 05/12/2022 under Order No.2114242632 which expires on 10/19/2022,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail copyright@aia.org. User Notes: (1429423941) § 8.7 Other provisions: The contractor shall coordinate the work of the Owner's consultants. ARTICLE 9 ENUMERATION OF CONTRACT DOCUMENTS § 9.1 This Agreement is comprised of the following documents: .1 AIA Document A101T"_2017, Standard Form of Agreement Between Owner and Contractor .2 AIA Document A101T`_2017, Exhibit A,Insurance and Bonds .3 AIA Document A20lTM-2017,General Conditions of the Contract for Construction .4 AIA Document E203T"4-2013,Building Information Modeling and Digital Data Exhibit,dated as indicated below: (Insert the date of the E203-2013 incorporated into this Agreement.) N/A .5 Drawings Number Title Date See Attached Exhibit'B': Riverside Public Safety Additions and Renovation Bid Set issued on March 14,2022 .6 Specifications Section Title Date Pages See Attached Exhibit'C': Divisions 1-33 of the Project Manual issued on March 14,2022 .7 Addenda, if any: Number Date Pages Addendum 1 4/1/22 6 Addendum 2 4/11/22 102 Addendum 3 4/15/22 13 Addendum 4 4/19/22 2 (Paragraph deleted) .8 Other Exhibits: (Check all boxes that apply and include appropriate information identifying the exhibit where required.) [ ] AIA Document E204Tm-2017,Sustainable Projects Exhibit,dated as indicated below: (Insert the date of the E204-2017 incorporated into this Agreement.) [ ] The Sustainability Plan: Title Date Pages [ X ] Supplementary and other Conditions of the Contract: Document Title Date Pages Supplementary Conditions have "Section 006001- 11/29/21 13 Init. AIA Document A101®—2017.Copyright©1915,1918,1925,1937,1951,1958,1961,1963,1967,1974,1977,1987,1991,1997,2007 and 2017 by The American Institute of Architects.All rights reserved.The"American Institute of Architects,""AIA,"the AIA Logo,"A101,"and"AIA Contract Documents"are 7 registered trademarks and may not be used without permission.This document was produced by AIA software at 09:36:29 ET on 05/12/2022 under Order No.2114242632 which expires on 10/19/2022,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail copyright@aia.org. User Notes: (1429423941) been incorporated into the AIA Supplementary Document A201 General Conditions Conditions to MA document and A101-Exhibit A for Document A201" insurance and bonds. .9 Other documents,if any,listed below: (List here any additional documents that are intended to form part of the Contract Documents.AIA Document A201 Tm-2017 provides that the advertisement or invitation to bid,Instructions to Bidders, sample forms, the Contractor's bid or proposal,portions of Addenda relating to bidding or proposal requirements,and other information furnished by the Owner in anticipation of receiving bids or proposals,are not part of the Contract Documents unless enumerated in this Agreement.Any such documents should be listed here only if intended to be part of the Contract Documents.) Contractor's Bid Form,Section 004113 Bid Form—Stipulated Sum Contractor's Unit Price Form,Section 004322 Unit Price Form Contractor's Alternates Form,Section 004323 Alternates Form Division 0-Procurement and Contracting Requirements of the Project Manual issued on 03/14/2022 This Agreement entered into as of the day and year first written above. City of Riverside Crossland Construction Company,Inc. i OWNER(Signature) CO CT0I (Signature) ,� lt)Ea L. Ras E f 1j o/z_ 7,� re,elrYkieUkl V la Preside!(Printed name and title) (Printed name and title) Init. AIA Document A101®—2017.Copyright©1915,1918,1925,1937,1951,1958,1961,1963,1967,1974,1977,1987,1991,1997,2007 and 2017 by The American Institute of Architects.All rights reserved.The"American Institute of Architects,""AIA,"the AIA Logo,"A101,"and"AIA Contract Documents"are 8 registered trademarks and may not be used without permission.This document was produced by AIA software at 09:36:29 ET on 05/12/2022 under Order No.2114242632 which expires on 10/19/2022,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail copyright@aia.org. User Notes: (1429423941) WOO AIA Document A101® - 2017 Exhibit A Insurance and Bonds This Insurance and Bonds Exhibit is part of the Agreement,between the Owner and the Contractor,dated the Sixteenth day of May in the year Two Thousand Twenty Two. (In words, indicate day, month and year.) ADDITIONS AND DELETIONS: for the following PROJECT: The author of this document has (Name and location or address) added information needed for its completion.The author may also have revised the text of the original Additions&Renovation AIA standard form.An Additions and Riverside Public Safety Deletions Report that notes added 2990 NW Vivion Road information as well as revisions to the Riverside,Missouri standard form text is available from the author and should be reviewed.A WSKF Project No.21010 vertical line in the left margin of this document indicates where the author THE OWNER: has added necessary information (Name, legal status and address) and where the author has added to or deleted from the original AIA text. City of Riverside,Missouri 2950 NW Vivion Road This document has important legal Riverside,MO consequences.Consultation with an attorney is encouraged with respect THE CONTRACTOR: to its completion or modification. (Name, legal status and address) This document is intended to be used in conjunction with AIA Document Crossland Construction Company,Inc. A201Ca� 2017,General Conditions of 833 S.East Avenue the Contract for Construction.Article Columbus,KS 66725 11 of A2010.2017 contains additional insurance provisions. TABLE OF ARTICLES A.1 GENERAL A.2 OWNER'S INSURANCE A.3 CONTRACTOR'S INSURANCE AND BONDS A.4 SPECIAL TERMS AND CONDITIONS ARTICLE A.1 GENERAL The Owner and Contractor shall purchase and maintain insurance,and provide bonds,as set forth in this Exhibit.As used in this Exhibit,the term General Conditions refers to AIA Document A201 TM-2017,General Conditions of the Contract for Construction. ARTICLE A.2 OWNER'S INSURANCE § A.2.1 General Prior to commencement of the Work,the Owner shall secure the insurance,and provide evidence of the coverage,required under this Article A.2 and,upon the Contractor's request,provide a copy of the property insurance policy or policies required by Section A.2.3.The copy of the policy or policies provided shall contain all applicable conditions, definitions,exclusions,and endorsements. Init. AIA Document A1018—2017 Exhibit A.Copyright©2017 by The American Institute of Architects.All rights reserved.The"American Institute of Architects,""AIA," the AIA Logo,"A101,"and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA software at 09:28:37 ET on 05/12/2022 under Order No.2114242632 which expires on 10/19/2022,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail copyright@aia.org. User Notes: (812077877) § A.2.2 Liability Insurance The Owner shall be responsible for purchasing and maintaining the Owner's usual general liability insurance. § A.2.3 Required Property Insurance § A.2.3.1 Unless this obligation is placed on the Contractor pursuant to Section A.3.3.2.1,the Owner shall purchase and maintain,from an insurance company or insurance companies lawfully authorized to issue insurance in the jurisdiction where the Project is located,property insurance written on a builder's risk"all-risks"completed value or equivalent policy form and sufficient to cover the total value of the entire Project on a replacement cost basis.The Owner's property insurance coverage shall be no less than the amount of the initial Contract Sum,plus the value of subsequent Modifications and labor performed and materials or equipment supplied by others.The property insurance shall be maintained until Substantial Completion and thereafter as provided in Section A.2.3.1.3,unless otherwise provided in the Contract Documents or otherwise agreed in writing by the parties to this Agreement.This insurance shall include the interests of the Owner,Contractor,Subcontractors,and Sub-subcontractors in the Project as insureds. This insurance shall include the interests of mortgagees as loss payees. § A.2.3.1.1 Causes of Loss.The insurance required by this Section A.2.3.1 shall provide coverage for direct physical loss or damage,and shall not exclude the risks of fire,explosion,theft,vandalism,malicious mischief,collapse, earthquake,flood,or windstorm.The insurance shall also provide coverage for ensuing loss or resulting damage from error,omission,or deficiency in construction methods,design,specifications,workmanship,or materials.Sub-limits, if any,are as follows: (Indicate below the cause of loss and any applicable sub-limit.) Causes of Loss Sub-Limit • None. § A.2.3.1.2 Specific Required Coverages.The insurance required by this Section A.2.3.1 shall provide coverage for loss or damage to falsework and other temporary structures,and to building systems from testing and startup.The insurance shall also cover debris removal,including demolition occasioned by enforcement of any applicable legal requirements,and reasonable compensation for the Architect's and Contractor's services and expenses required as a result of such insured loss,including claim preparation expenses.Sub-limits,if any,are as follows: (Indicate below type of coverage and any applicable sub-limit for specific required coverages.) Coverage Sub-Limit None. § A.2.3.1.3 Unless the parties agree otherwise,upon Substantial Completion,the Owner shall continue the insurance required by Section A.2.3.1 or,if necessary,replace the insurance policy required under Section A.2.3.1 with property insurance written for the total value of the Project that shall remain in effect until expiration of the period for correction of the Work set forth in Section 12.2.2 of the General Conditions. § A.2.3.1.4 Deductibles and Self-Insured Retentions.If the insurance required by this Section A.2.3 is subject to deductibles or self-insured retentions,the Owner shall be responsible for all loss not covered because of such deductibles or retentions. § A.2.3.2 Occupancy or Use Prior to Substantial Completion.The Owner's occupancy or use of any completed or partially completed portion of the Work prior to Substantial Completion shall not commence until the insurance company or companies providing the insurance under Section A.2.3.1 have consented in writing to the continuance of coverage,except that Owner and its designee(s)may,as needed and without written notice to or written consent by the insurance company,access rooms and portions of rooms not being renovated in order to access,remove,and/or store equipment,records,and vehicles stored and/or kept therein.The Owner and the Contractor shall take no action with respect to partial occupancy or use that would cause cancellation,lapse,or reduction of insurance,unless they agree otherwise in writing. AIA Document A1010—2017 Exhibit A.Copyright©2017 by The American Institute of Architects.All rights reserved.The'American Institute of Architects,""AIA,' the AIA Logo,"A101,"and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA 2 software at 09:28:37 ET on 05/12/2022 under Order No.2114242632 which expires on 10/19/2022,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents°Terms of Service.To report copyright violations,e-mail copyright@aia.org. User Notes: (812077877) § A.2.3.3 Insurance for Existing Structures If the Work involves remodeling an existing structure or constructing an addition to an existing structure,the Owner shall purchase and maintain,until the expiration of the period for correction of Work as set forth in Section 12.2.2 of the General Conditions,"all-risks"property insurance,on a replacement cost basis,protecting the existing structure against direct physical loss or damage from the causes of loss identified in Section A.2.3.1,notwithstanding the undertaking of the Work.The Owner shall be responsible for all co-insurance penalties. (Paragraphs deleted) ARTICLE A.3 CONTRACTOR'S INSURANCE AND BONDS § A.3.1 General § A.3.1.1 Certificates of Insurance.The Contractor shall provide certificates of insurance acceptable to the Owner evidencing compliance with the requirements in this Article A.3 at the following times:(1)prior to commencement of the Work;(2)upon renewal or replacement of each required policy of insurance;and(3)upon the Owner's written request.An additional certificate evidencing continuation of commercial liability coverage,including coverage for completed operations,shall be submitted with the final Application for Payment and thereafter upon renewal or replacement of such coverage until the expiration of the periods required by Section A.3.2.1 and Section A.3.3.1.The certificates will show the Owner as an additional insured on the Contractor's Commercial General Liability and excess or umbrella liability policy or policies. § A.3.1.2 Deductibles and Self-Insured Retentions.The Contractor shall disclose to the Owner any deductible or self- insured retentions applicable to any insurance required to be provided by the Contractor. § A.3.1.3 Additional Insured Obligations.To the fullest extent permitted by law,the Contractor shall cause the commercial general liability coverage to include(1)the Owner,the Architect,and the Architect's consultants as additional insureds for claims caused in whole or in part by the Contractor's negligent acts or omissions during the Contractor's operations;and(2)the Owner as an additional insured for claims caused in whole or in part by the Contractor's negligent acts or omissions for which loss occurs during completed operations.The additional insured coverage shall be primary and non-contributory to any of the Owner's general liability insurance policies and shall apply to both ongoing and completed operations.To the extent commercially available,the additional insured coverage shall be no less than that provided by Insurance Services Office,Inc.(ISO)forms CG 20 10 07 04,CG 20 37 07 04,and,with respect to the Architect and the Architect's consultants,CG 20 32 07 04.All required insurance shall be provided by companies that have a current A.M.Best insurance rating of A-or better and that are licensed or approved to do business in the State of Missouri. § A.3.2 Contractor's Required Insurance Coverage § A.3.2.1 The Contractor shall purchase and maintain the following types and limits of insurance from an insurance company or insurance companies lawfully authorized to issue insurance in the jurisdiction where the Project is located.The Contractor shall maintain the required insurance until the expiration of the period for correction of Work as set forth in Section 12.2.2 of the General Conditions,unless a different duration is stated below: (If the Contractor is required to maintain insurance for a duration other than the expiration of the period for correction of Work,state the duration.) § A.3.2.2 Commercial General Liability § A.3.2.2.1 Commercial General Liability insurance for the Project written on an occurrence form with policy limits of not less than One Million Dollars and 00/100's($1,000,000.00)each occurrence,Two Million Dollars and 00/100's ($2,000,000.00)general aggregate,and Three Million Dollars and 00/100's($3,000,000.00)aggregate for products-completed operations hazard,providing coverage for claims including .1 damages because of bodily injury,sickness or disease,including occupational sickness or disease,and death of any person; .2 personal injury and advertising injury; .3 damages because of physical damage to or destruction of tangible property,including the loss of use of such property; .4 bodily injury or property damage arising out of completed operations;and Init. AIA Document A101•—2017 Exhibit A.Copyright©2017 by The American Institute of Architects.All rights reserved.The"American Institute of Architects,""AIA," the AIA Logo,"A101."and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA 3 software at 0928 37 ET on 05/12/2022 under Order No.2114242632 which expires on 10/19/2022,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail copyright@aia.org. User Notes: (812077877) .5 the Contractor's indemnity obligations under Section 3.18 of the General Conditions. § A.3.2.2.2 The Contractor's Commercial General Liability policy under this Section A.3.2.2 shall not contain an exclusion or restriction of coverage for the following: .1 Claims by one insured against another insured,if the exclusion or restriction is based solely on the fact that the claimant is an insured,and there would otherwise be coverage for the claim. .2 Claims for property damage to the Contractor's Work arising out of the products-completed operations hazard where the damaged Work or the Work out of which the damage arises was performed by a Subcontractor. .3 Claims for bodily injury other than to employees of the insured. .4 Claims for indemnity under Section 3.18 of the General Conditions arising out of injury to employees of the insured. .5 Claims or loss excluded under a prior work endorsement or other similar exclusionary language. .6 Claims or loss due to physical damage under a prior injury endorsement or similar exclusionary language. .7 Claims related to roofing,if the Work involves roofing. (Paragraph deleted) .8 Claims related to earth subsidence or movement,where the Work involves such hazards. .9 Claims related to explosion,collapse and underground hazards,where the Work involves such hazards. § A.3.2.3 Automobile Liability covering vehicles owned,and non-owned vehicles used,by the Contractor,with policy limits of not less than One Million Dollars and 00/100's($1,000,000.00)per accident,for bodily injury,death of any person,and property damage arising out of the ownership,maintenance and use of those motor vehicles along with any other statutorily required automobile coverage. § A.3.2.4 The Contractor may achieve the required limits and coverage for Commercial General Liability and Automobile Liability through a combination of primary and excess or umbrella liability insurance,provided such primary and excess or umbrella insurance policies result in the same or greater coverage as the coverages required under Section A.3.2.2 and A.3.2.3,and in no event shall any excess or umbrella liability insurance provide narrower coverage than the primary policy.The excess policy shall not require the exhaustion of the underlying limits only through the actual payment by the underlying insurers. § A.3.2.5 Workers'Compensation at statutory limits. § A.3.2.6 Employers'Liability with policy limits not less than One Million Dollars and 00/100's($1,000,000.00)each accident,One Million Dollars and 00/100's($1,000,000.00)each employee,and One Million Dollars and 00/100's ($1,000,000.00)policy limit. (Paragraph deleted) § A.3.2.8 If the Contractor is required to furnish professional services as part of the Work,the Contractor shall procure Professional Liability insurance covering performance of the professional services,with policy limits of not less than One Million Dollars and 00/100's($1,000,000.00)per claim and One Million Dollars and 00/100's($1,000,000.00)in the aggregate. (Paragraphs deleted) § A.3.3 Contractor's Other Insurance Coverage § A.3.3.1 Insurance selected and described in this Section A.3.3 shall be purchased from an insurance company or insurance companies lawfully authorized to issue insurance in the jurisdiction where the Project is located.The Contractor shall maintain the required insurance until the expiration of the period for correction of Work as set forth in Section 12.2.2 of the General Conditions,unless a different duration is stated below: (If the Contractor is required to maintain any of the types of insurance selected below for a duration other than the expiration of the period for correction of Work,state the duration.) Umbrella Excess Liability-Two Million Dollars and 00/100's($2,000,000.00). Init. AIA Document A1018—2017 Exhibit A.Copyright©2017 by The American Institute of Architects.All rights reserved.The"American Institute of Architects,""AIA," the AIA Logo,"A101,"and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA 4 software at 09:28:37 ET on 05/12/2022 under Order No.2114242632 which expires on 10/19/2022,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail copyright@aia.org. User Notes: (812077877) § A.3.3.2 The Contractor shall purchase and maintain the following types and limits of insurance in accordance with Section A.3.3.1. (Select the types of insurance the Contractor is required to purchase and maintain by placing an X in the box(es)next to the description(s)of selected insurance. Where policy limits are provided, include the policy limit in the appropriate fill point.) [ X ] § A.3.3.2.1 Property insurance of the same type and scope satisfying the requirements identified in Section A.2.3,which,if selected in this section A.3.3.2.1,relieves the Owner of the responsibility to purchase and maintain such insurance except insurance required by Section A.2.3.1.3 and Section A.2.3.3. The Contractor shall comply with all obligations of the Owner under Section A.2.3 except to the extent provided below.The Contractor shall disclose to the Owner the amount of any deductible, and the Owner shall be responsible for losses within the deductible.Upon request,the Contractor shall provide the Owner with a copy of the property insurance policy or policies required.The Owner shall adjust and settle the loss with the insurer and be the trustee of the proceeds of the property insurance in accordance with Article 11 of the General Conditions unless otherwise set forth below: (Where the Contractor's obligation to provide property insurance differs from the Owner's obligations as described under Section A.2.3, indicate such differences in the space below.Additionally, if a party other than the Owner will be responsible for adjusting and settling a loss with the insurer and acting as the trustee of the proceeds of property insurance in accordance with Article 11 of the General Conditions, indicate the responsible party below.) None. [ X ] § A.3.3.2.4 Insurance for physical damage to property while it is in storage and in transit to the construction site on an"all-risks"completed value form. [ X ] § A.3.3.2.5 Property insurance on an"all-risks"completed value form,covering property owned by the Contractor and used on the Project,including scaffolding and other equipment. [ ] § A.3.3.2.6 Other Insurance (List below any other insurance coverage to be provided by the Contractor and any applicable limits.) Coverage Limits None. § A.3.4 Performance Bond and Payment Bond The Contractor shall provide surety bonds,from a company or companies lawfully authorized to issue surety bonds in the jurisdiction where the Project is located,and the Contractor shall furnish a Performance Bond and a Payment Bond covering the faithful performance of the Contract and payment obligations arising therefrom. Bonds may be obtained through the Contractor's usual source and the cost thereof shall be included in the Contract Sum.The amount of each bond shall be equal to 100%of the Contract Sum. Should the Contract Sum change during the contract and warranty periods,the amount of the Bonds will be changed to reflect the Contract Sum. (Table deleted) .1 The Contractor shall deliver the required bonds to the Owner at the same time as the signed Contract Agreement is delivered to the Owner. Prior to the commencement of the Work,the Contractor shall submit satisfactory evidence that such bonds will be furnished. .2 The contractor shall require the attorney-in-fact who executes the required bonds on behalf of the surety to affix thereto a certified and current copy of the power of attorney. .3 The Contractor Bonds shall continue in effect for one year after final acceptance of each contract to protect the Owner's interest in connection with the one year guarantee of workmanship and materials and to assure settlement of claims,for the payment of all bills for labor,materials,and equipment by the Contractor. ARTICLE A.4 SPECIAL TERMS AND CONDITIONS Special terms and conditions that modify this Insurance and Bonds Exhibit,if any,are as follows: Init. AIA Document A101®—2017 Exhibit A.Copyright©2017 by The American Institute of Architects.All rights reserved.The"American Institute of Architects,""AIA," the AIA Logo,"A101,"and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA 5 software at 09:28:37 ET on 05/12/2022 under Order No.2114242632 which expires on 10/19/2022,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail copyright@aia.org. User Notes: (812077877) None. AIA Document A101e—2017 Exhibit A.Copyright©2017 by The American Institute of Architects.All rights reserved.The"American Institute of Architects,""AIA," Init. the AIA Logo."A101,"and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA 6 software at 09 28,37 ET on 05/12/2022 under Order No.2114242632 which expires on 10/19/2022,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail copyright@aia.org. User Notes: (812077877) • Bond No.K40564822/09404517 -$1"� I Document A312TM - 2010 Performance Bond CONTRACTOR: SURETY: (Name, legal status and address) (Name, legal status and principal place Crossland Construction Company,Inc. of business) 833 S.East Avenue Federal Insurance Company Columbus,KS 66725 202B Hall's Mill Road,Whitehouse Station,NJ 08889/This document has important legal Fidelity and Deposit Company of Maryland consequences.Consultation with OWNER: 1299 Zurich Way,5th Floor,Schaumburg,IL 60196 an attorney is encouraged with respect to its completion or (Name, legal status and address) modification. City of Riverside,Missouri Any singular reference to 2950 NW Vivion Road Contractor,Surety,Owner or Riverside,MO other party shall be considered CONSTRUCTION CONTRACT plural where applicable. Date:May 16,2022 AIA Document A312-2010 combines two separate bonds,a Amount:Four Million Seven Hundred Seventeen Thousand and 00/100 Dollars Performance Bond and a Payment Bond,into one form. Description: This is not a single combined (Name and location) Performance and Payment Bond. Additions and Renovation,Riverside Public Safety 2990 NW Vivion Road,Riverside,Missouri WSKF Project No.21010 BOND Date:June 7,2022 (Not earlier than Construction Contract Date) Amount:Four Million Seven Hundred Seventeen Thousand and 00/100 Dollars Modifications to this Bond: El None 0 See Section 16 CONTRACTOR AS PRINCIPAL SURETY company:. (Corporate Seal) Company: (Corporate Seal) _ ^' Crossland Construction Co pany,Inc. Federal Insurance Company/Fidelity and Deposit Company of Maryland Srgnatur6't Signature: •- Name =- van C 4, (.Cti Name Camille O.Parman and Title:: and Title: Attorney-in-Fact • --(Any additional signatures appear on the last page of this Performance Bond) (FOR INFORMATION ONLY—Name,address and telephone) -- AGENT or BROKER: OWNER'S REPRESENTATIVE: IMA Inc. (Architect,Engineer or other party.) 51 Corporate Woods Mr.Travis Hoover,City Engineer 9393 W. 110th Street,Suite 600 City of Riverside,Missouri Overland Park,KS 66210 2950 NW Vivion Road 913-982-3650 Riverside,Missouri Init. AIA Document A312T"'—2010.The American Institute of Architects. 061110 1 §1 The Contractor and Surety,jointly and severally,bind themselves,their heirs,executors,administrators,successors and assigns to the Owner for the performance of the Construction Contract,which is incorporated herein by reference. §2 If the Contractor performs the Construction Contract,the Surety and the Contractor shall have no obligation under this Bond,except when applicable to participate in a conference as provided in Section 3. §3 If there is no Owner Default under the Construction Contract,the Surety's obligation under this Bond shall arise after .1 the Owner first provides notice to the Contractor and the Surety that the Owner is considering declaring a Contractor Default.Such notice shall indicate whether the Owner is requesting a conference among the Owner,Contractor and Surety to discuss the Contractor's performance.If the Owner does not request a conference,the Surety may,within five(5)business days after receipt of the Owner's notice, request such a conference.If the Surety timely requests a conference,the Owner shall attend.Unless the Owner agrees otherwise,any conference requested under this Section 3.1 shall be held within ten (10)business days of the Surety's receipt of the Owner's notice.If the Owner,the Contractor and the Surety agree,the Contractor shall be allowed a reasonable time to perform the Construction Contract, but such an agreement shall not waive the Owner's right,if any,subsequently to declare a Contractor Default; .2 the Owner declares a Contractor Default,terminates the Construction Contract and notifies the Surety; and .3 the Owner has agreed to pay the Balance of the Contract Price in accordance with the terms of the Construction Contract to the Surety or to a contractor selected to perform the Construction Contract. §4 Failure on the part of the Owner to comply with the notice requirement in Section 3.1 shall not constitute a failure to comply with a condition precedent to the Surety's obligations,or release the Surety from its obligations,except to the extent the Surety demonstrates actual prejudice. §5 When the Owner has satisfied the conditions of Section 3,the Surety shall promptly and at the Surety's expense take one of the following actions: §5.1 Arrange for the Contractor,with the consent of the Owner,to perform and complete the Construction Contract; §5.2 Undertake to perform and complete the Construction Contract itself,through its agents or independent contractors; §5.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for performance and completion of the Construction Contract,arrange for a contract to be prepared for execution by the Owner and a contractor selected with the Owner's concurrence,to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract,and pay to the Owner the amount of damages as described in Section 7 in excess of the Balance of the Contract Price incurred by the Owner as a result of the Contractor Default;or §5.4 Waive its right to perform and complete,arrange for completion,or obtain a new contractor and with reasonable promptness under the circumstances: .1 After investigation,determine the amount for which it may be liable to the Owner and,as soon as practicable after the amount is determined,make payment to the Owner;or .2 Deny liability in whole or in part and notify the Owner,citing the reasons for denial. §6 If the Surety does not proceed as provided in Section 5 with reasonable promptness,the Surety shall be deemed to be in default on this Bond seven days after receipt of an additional written notice from the Owner to the Surety demanding that the Surety perform its obligations under this Bond,and the Owner shall be entitled to enforce any remedy available to the Owner.If the Surety proceeds as provided in Section 5.4,and the Owner refuses the payment or the Surety has denied liability,in whole or in part,without further notice the Owner shall be entitled to enforce any remedy available to the Owner. Init. AIA Document A312TM'—2010.The American Institute of Architects. 2 §7 If the Surety elects to act under Section 5.1,5.2 or 5.3,then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction Contract,and the responsibilities of the Owner to the Surety shall not be greater than those of the Owner under the Construction Contract.Subject to the commitment by the Owner to pay the Balance of the Contract Price,the Surety is obligated,without duplication,for .1 the responsibilities of the Contractor for correction of defective work and completion of the Construction Contract; .2 additional legal,design professional and delay costs resulting from the Contractor's Default,and resulting from the actions or failure to act of the Surety under Section 5;and .3 liquidated damages,or if no liquidated damages are specified in the Construction Contract,actual damages caused by delayed performance or non-performance of the Contractor. §8 If the Surety elects to act under Section 5.1,5.3 or 5.4,the Surety's liability is limited to the amount of this Bond. §9 The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the Construction Contract,and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations.No right of action shall accrue on this Bond to any person or entity other than the Owner or its heirs,executors,administrators,successors and assigns. §10 The Surety hereby waives notice of any change,including changes of time,to the Construction Contract or to related subcontracts,purchase orders and other obligations. §11 Any proceeding,legal or equitable,under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or part of the work is located and shall be instituted within two years after a declaration of Contractor Default or within two years after the Contractor ceased working or within two years after the Surety refuses or fails to perform its obligations under this Bond,whichever occurs first.If the provisions of this Paragraph are void or prohibited by law,the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. §12 Notice to the Surety,the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. §13 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed,any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein.When so furnished,the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. §14 Definitions §14.1 Balance of the Contract Price.The total amount payable by the Owner to the Contractor under the Construction Contract after all proper adjustments have been made,including allowance to the Contractor of any amounts received or to be received by the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled,reduced by all valid and proper payments made to or on behalf of the Contractor under the Construction Contract. §14.2 Construction Contract.The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and changes made to the agreement and the Contract Documents. §14.3 Contractor Default.Failure of the Contractor,which has not been remedied or waived,to perform or otherwise to comply with a material term of the Construction Contract. §14.4 Owner Default.Failure of the Owner,which has not been remedied or waived,to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. §14.5 Contract Documents.All the documents that comprise the agreement between the Owner and Contractor. §15 If this Bond is issued for an agreement between a Contractor and subcontractor,the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. Init. AIA Document A312TM—2010.The American Institute of Architects. 3 §16 Modifications to this bond are as follows: (Space is provided below for additional signatures of added parties, other than those appearing on the cover page) CONTRACTOR AS PRINCIPAL SURETY Company: (Co porate Seal) Company: (Corporate Seal) Signature: N/A Signature: N/A Name and Title: Name and Title: Address Address CAUTION:You should sign an original AIA Contract Document,on which this text appears in RED.An original assures that changes will not be obscured. Init. AlA Document A312T°'—2010.The American Institute of Architects. 4 Bond No.K40564822/09404517 TAIA Document A312TM - 2010 Payment Bond CONTRACTOR: SURETY: (Name, legal status and address) (Name, legal status and principal place Crossland Construction Company,Inc. of business) 833 S.East Avenue Federal Insurance Company Columbus,KS 66725 202B Hall's Mill Road,Whitehouse Station,NJ 08889/This document has important legal Fidelity and Deposit Company of Maryland consequences.Consultation with OWNER: 1299 Zurich Way.5th Floor,Schaumburg,IL 60196 an attorney is encouraged with respect to its completion or (Name, legal status and address) modification. City of Riverside,Missouri Any singular reference to 2950 NW Vivion Road Contractor,Surety,Owner or Riverside,MO other party shall be considered CONSTRUCTION CONTRACT plural where applicable. Date: May 16,2022 AlA Document A312-2010 combines two separate bonds,a Amount:Four Million Seven Hundred Seventeen Thousand and 00/100 Dollars Performance Bond and a Payment Bond,into one form. Description: This is not a single combined (Name and location) Performance and Payment Bond. Additions and Renovation,Riverside Public Safety 2990 NW Vivion Road,Riverside,Missouri WSKF Project No.21010 BOND Date:June 7,2022 (Not earlier than Construction Contract Date) Amount:Four Million Seven Hundred Seventeen Thousand and 00/100 Dollars Modifications to this Bond: ®None ❑ See Section 18 •-- CONTRACTOR AS PRINCIPAL SURETY _ Company: (Corporate Seal) Company: (Corporate Seal) - Crossland Con truction Comp y,Inc. ederal Insurance Company/Fidelity and Deposit Company of Maryland Signature:„„ J ignature: y��• /2 - _ Name _ ame Camille O.Parman %. •-- and Title-:yV0.ik Lt056 ,R.6( . C6C) and Title: Attorney-in-Fact _ _ (Any additional signatures appear on the la t page of this Payment Bond.) - - - -(FOR INFORMATION ONLY—Name, address and telephone) —AGENT or BROKER: OWNER'S REPRESENTATIVE: IMA,Inc. (Architect,Engineer or other party.) 51 Corporate Woods, Mr.Travis Hoover,City Engineer .; T 9393 W. 110th Street,Suite 600 City of Riverside,Missouri Overland Park,KS 66210 2950 NW Vivion Road 913-982-3650 Riverside,Missouri Init. AIA Document A312T'"—2010.The American Institute of Architects. 061110 5 §1 The Contractor and Surety,jointly and severally,bind themselves,their heirs,executors,administrators,successors and assigns to the Owner to pay for labor,materials and equipment furnished for use in the performance of the • Construction Contract,which is incorporated herein by reference,subject to the following terms. §2 If the Contractor promptly makes payment of all sums due to Claimants,and defends,indemnifies and holds harmless the Owner from claims,demands,liens or suits by any person or entity seeking payment for labor,materials or equipment furnished for use in the performance of the Construction Contract,then the Surety and the Contractor shall have no obligation under this Bond. §3 If there is no Owner Default under the Construction Contract,the.Surety's obligation to the Owner under this Bond shall arise after the Owner has promptly notified the Contractor and the Surety(at the address described in Section 13) of claims,demands,liens or suits against the Owner or the Owner's property by any person or entity seeking payment for labor,materials or equipment furnished for use in the performance of the Construction Contract and tendered defense of such claims,demands,liens or suits to the Contractor and the Surety. §4 When the Owner has satisfied the conditions in Section 3,the Surety shall promptly and at the Surety's expense defend,indemnify and hold harmless the Owner against a duly tendered claim,demand,lien or suit. §5 The Surety's obligations to a Claimant under this Bond shall arise after the following: §5.1 Claimants,who do not have a direct contract with the Contractor, .1 have furnished a written notice of non-payment to the Contractor,stating with substantial accuracy the amount claimed and the name of the party to whom the materials were,or equipment was,furnished or supplied or for whom the labor was done or performed,within ninety(90)days after having last performed labor or last furnished materials or equipment included in the Claim;and .2 have sent a Claim to the Surety(at the address described in Section 13). §5.2 Claimants,who are employed by or have a direct contract with the Contractor,have sent a Claim to the Surety(at the address described in Section 13). §6 If a notice of non-payment required by Section 5.1.1 is given by the Owner to the Contractor,that is sufficient to satisfy a Claimant's obligation to furnish a written notice of non-payment under Section 5.1.1. §7 When a Claimant has satisfied the conditions of Sections 5.1 or 5.2,whichever is applicable,the Surety shall promptly and at the Surety's expense take the following actions: §7.1 Send an answer to the Claimant,with a copy to the Owner,within sixty(60)days after receipt of the Claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed;and §7.2 Pay or arrange for payment of any undisputed amounts. §7.3 The Surety's failure to discharge its obligations under Section 7.1 or Section 7.2 shall not be deemed to constitute a waiver of defenses the Surety or Contractor may have or acquire as to a Claim,except as to undisputed amounts for which the Surety and Claimant have reached agreement.If,however,the Surety fails to discharge its obligations under Section 7.1 or Section 7.2,the Surety shall indemnify the Claimant for the reasonable attorney's fees the Claimant incurs thereafter to recover any sums found to be due and owing to the Claimant. §8 The Surety's total obligation shall not exceed the amount of this Bond,plus the amount of reasonable attorney's fees provided under Section 7.3,and the amount of this Bond shall be credited for any payments made in good faith by the Surety. §9 Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the performance of the Construction Contract and to satisfy claims,if any,under any construction performance bond.By the Contractor furnishing and the Owner accepting this Bond,they agree that all funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and Surety under this Bond,subject to the Owner's priority to use the funds for the completion of the work. Init. AIA Document A312TM"—2010.The American Institute of Architects. 6 §10 The Surety shall not be liable to the Owner,Claimants or others for obligations of the Contractor that are unrelated to the Construction Contract.The Owner shall not be liable for the payment of any costs or expenses of any Claimant under this Bond,and shall have under this Bond no obligation to make payments to,or give notice on behalf of,Claimants or otherwise have any obligations to Claimants under this Bond. §11 The Surety hereby waives notice of any change,including changes of time,to the Construction Contract or to related subcontracts,purchase orders and other obligations. §12 No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the state in which the project that is the subject of the Construction Contract is located or after the expiration of one year from the date(1)on which the Claimant sent a Claim to the Surety pursuant to Section 5.1.2 or 5.2,or(2)on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construction Contract,whichever of(1)or(2)first occurs.If the provisions of this Paragraph are void or prohibited by law,the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. §13 Notice and Claims to the Surety,the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears.Actual receipt of notice or Claims,however accomplished,shall be sufficient compliance as of the date received. §14 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed,any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein.When so furnished,the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. §15 Upon request by any person or entity appearing to be a potential beneficiary of this Bond,the Contractor and Owner shall promptly furnish a copy of this Bond or shall permit a copy to be made. §16 Definitions §16.1 Claim.A written statement by the Claimant including at a minimum: .1 the name of the Claimant; .2 the name of the person for whom the labor was done,or materials or equipment furnished; .3 a copy of the agreement or purchase order pursuant to which labor,materials or equipment was furnished for use in the performance of the Construction Contract; .4 a brief description of the labor,materials or equipment furnished; .5 the date on which the Claimant last performed labor or last furnished materials or equipment for use in the performance of the Construction Contract; .6 the total amount earned by the Claimant for labor,materials or equipment furnished as of the date of the Claim; .7 the total amount of previous payments received by the Claimant;and .8 the total amount due and unpaid to the Claimant for labor,materials or equipment furnished as of the date of the Claim. §16.2 Claimant.An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to furnish labor,materials or equipment for use in the performance of the Construction Contract.The term Claimant also includes any individual or entity that has rightfully asserted a claim under an applicable mechanic's lien or similar statute against the real property upon which the Project is located.The intent of this Bond shall be to include without limitation in the terms"labor,materials or equipment"that part of water,gas,power,light,heat,oil, gasoline,telephone service or rental equipment used in the Construction Contract,architectural and engineering services required for performance of the work of the Contractor and the Contractor's subcontractors,and all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor,materials or equipment were furnished. §16.3 Construction Contract.The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and all changes made to the agreement and the Contract Documents. Init. AIA Document A312TM—2010.The American Institute of Architects. 7 • §16.4 Owner Default.Failure of the Owner,which has not been remedied or waived,to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. §16.5 Contract Documents.All the documents that comprise the agreement between the Owner and Contractor. §17 If this Bond is issued for an agreement between a Contractor and subcontractor,the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. §18 Modifications to this bond are as follows: (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corpor•ate Seal) Company: (Corporate Seal) Signature: N/A Signature: N/A Name and Title: Name and Title: Address Address CAUTION:You should sign an original AIA Contract Document,on which this text appears in RED.An original assures that changes will not be obscured. Init. AIA Document A312TM—2010.The American Institute of Architects. 8 CHUBB' Power of Attorney Federal Insurance Company I Vigilant Insurance Company I Pacific Indemnity Company Westchester Fire Insurance Company I ACE American Insurance Company Know All by These Presents,that FEDERAL INSURANCE COMPANY,an Indiana corporation,VIGILANT INSURANCE COMPANY,a New York corporation,PACIFIC INDEMNITY COMPANY,a Wisconsin corporation,WESTCHESTER FIRE INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY corporations of the Commonwealth of Pennsylvania, do each hereby constitute and appoint Bret S. Burton, Timothy H. Heffel, Todd Alan Rambo, Timothy Craig Smith, Myriah A. Valdivia and Desiree E. Westmoreland of Wichita, Kansas; Katherine J. Breit, Monica F. Donatelli, Carolyn J. Johnson, Camille O. Parman, Morgan L.Wilkerson and S.Mark Wilkerson of Overland Park,Kansas each as their true and lawful Attorney-in-Fact to execute under such designation in their names and to affix their corporate seals to and deliver for and on their behalf as surety thereon or otherwise,bonds and undertakings and other writings obligatory in the nature thereof(other than bail bonds)given or executed in the course of business,and any instruments amending or altering the same,and consents to the modification or alteration of any instrument referred to in said bonds or obligations. In Witness Whereof,said FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,PACIFIC INDEMNITY COMPANY,WESTCHESTER FIRE INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY have each executed and attested these presents and affixed their corporate seals on this 21.day of December 2020. . \.lW..eL� .�-'MTV Dawn NI.Chloros.Assistant Secretary Stephen NI.Ilaney.Vice',resident fir"'a rip �p S°no4 J0w'Nr ,ems pJ�'�� ® • '� 4• 5c'ser�ck ® t 7 �; • STATE OF NEW JERSEY County of Hunterdon SS. On this 21.day of December,2020 before me,a Notary Public of New Jersey,personally came Dawn M.Chloros and Stephen M.Haney,to me known to be Assistant Secretary and Vice President,respectively,of FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,PACIFIC INDEMNITY COMPANY,WESTCHESTER FIRE INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY,the companies which executed the foregoing Power of Attorney,and the said Dawn M.Chloros and Stephen M.Haney,being by me duly sworn, severally and each for herself and himself did depose and say that they are Assistant Secretary and Vice President,respectively,of FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,PACIFIC INDEMNITY COMPANY,WESTCHESTER FIRE INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY and know the corporate seals thereof,that the seals affixed to the foregoing Power of Attorney are such corporate seals and were thereto affixed by authority of said Companies;and that their signatures as such officers were duly affixed and subscribed by like authority. Notarial Seal ,0 'd04.,� KATHERINE J.ADELAAR -rAAY NOTARY PUBLIC OF NEW JERSEY No.2316685 PUBLIC Commission Expires July 16,2024 Notary Public CERTIFICATION Resolutions adopted by the Boards of Directors of FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,and PACIFIC INDEMNITY COMPANY on August 30,2016; WESTCHESTER FIRE INSURANCE COMPANY on December 11,2006;and ACE AMERICAN INSURANCE COMPANY on March 20,2009: "RESOLVED,that the following authorizations relate to the execution,for and on behalf of the Company,of bonds,undertakings,recognizances,contracts and other written commitments of the Company entered into in the ordinary course of business(each a"Written Commitment"): (1) Each of the Chairman,the President and the Vice Presidents of the Company is hereby authorized to execute any Written Commitment for and on behalf of the Company,under the seal of the Company or otherwise.(2) Each duly appointed attorney-in-fact of the Company is hereby authorized to execute any Written Commitment for and on behalf of the Company,under the seal of the Company or otherwise, to the extent that such action is authorized by the grant of powers provided for in such person's written appointment as such attorney-in-fact. (3) Each of the Chairman,the President and the Vice Presidents of the Company is hereby authorized,for and on behalf of the Company,to appoint in writing any person the attorney-in- fact of the Company with full power and authority to execute,for and on behalf of the Company,under the seal of the Company or otherwise,such Written Commitments of the Company as may be specified in such written appointment,which specification may be by general type or class of Written Commitments or by specification of one or more particular Written Commitments. (4) Each of the Chairman,the President and the Vice Presidents of the Company is hereby authorized,for and on behalf of the Company,to delegate In writing to any other officer of the Company the authority to execute,for and on behalf of the Company,under the Company's seal or otherwise,such Written Commitments of the Company as are specified in such written delegation,which specification may he by general type or class of Written Commitments or by specification of one or more particular Written Commitments. (5) The signature of any officer or other person executing any Written Commitment or appointment or delegation pursuant to this Resolution,and the seal of the Company,may be affixed by facsimile on such Written Commitment or written appointment or delegation. FURTHER RESOLVED,that the foregoing Resolution shall not be deemed to be an exclusive statement of the powers and authority of officers,employees and other persons to act for and on behalf of the Company,and such Resolution shall not limit or otherwise affect the exercise of any such power or authority otherwise validly granted or vested." I,Dawn M.Chloros,Assistant Secretary of FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,PACIFIC INDEMNITY COMPANY,WESTCHESTER FIRE INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY(the"Companies")do hereby certify that (i) the foregoing Resolutions adopted by the Board of Directors of the Companies are true,correct and in full force and effect, • (ii) the foregoing Power of Attorney is true,correct and in full force and effect. Given under my hand and seals of said Companies at Whitehouse Station,NJ,this 7th day of June, 2022 41 el*, ("1;:j toi, en) 5\19:vuel( aiwn NI.Chloros.Assistant Secretor? IN THE EVENT YOU WISH TO VERIFY THE AUTHENTICITY OF THIS BOND OR NOTIFY US OF ANY OTHER MATTER PLEASE CONTACT US AT: Telephone(908)903-3493 Fax(908)903-3656 e-mail:surety@chubb.com - Combined:FED-VIG-PI-VVFIC-AAIC(rev.11-19) ZURICH AMERICAN INSURANCE COMPANY COLONIAL AMERICAN CASUALTY AND SURETY COMPANY FIDELITY AND DEPOSIT COMPANY OF MARYLAND POWER OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS:That the ZURICH AMERICAN INSURANCE COMPANY,a corporation of the State of New York, the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, a corporation of the State of Illinois, and the FIDELITY AND DEPOSIT COMPANY OF MARYLAND a corporation of the State of Illinois (herein collectively called the "Companies"), by Robert D.Murray,Vice President,in pursuance of authority granted by Article V,Section 8,of the By-Laws of said Companies,which are set forth on the reverse side hereof and are hereby certified to be in full force and effect on the date hereof,do hereby nominate,constitute, and appoint S.Mark WILKERSON,Kelly E.KIMMEL,Morgan DEWEY,Monica F.DONATELLI,Debra L.WALZ,Carolyn J. JOHNSON,Katherine J. BREIT,Camille O.PARMAN, Morgan L.WILKERSON of Overland Park,Kansas,EACH, its true and lawful agent and Attomey-in-Fact,to make, execute,seal and deliver,for,and on its behalf as surety,and as its act and deed: any and all bonds and undertakings,and the execution of such bonds or undertakings in pursuance of these presents, shall be as binding upon said Companies, as fully and amply,to all intents and purposes, as if they had been duly executed and acknowledged by the regularly elected officers of the ZURICH AMERICAN INSURANCE COMPANY at its office in New York,New York.,the regularly elected officers of the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY at its office in Owings Mills, Maryland., and the regularly elected officers of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND at its office in Owings Mills, Maryland., in their own proper persons. The said Vice President does hereby certify that the extract set forth on the reverse side hereof is a true copy of Article V,Section 8,of the By-Laws of said Companies,and is now in force. IN WITNESS WHEREOF,the said Vice-President has hereunto subscribed his/her names and affixed the Corporate Seals of the said ZURICH AMERICAN INSURANCE COMPANY, COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, and FIDELITY AND DEPOSIT COMPANY OF MARYLAND,this 03rd day of March,A.D.2021. ,g.,,.„.. .} •bow: �J ATTEST: ZURICH AMERICAN INSURANCE COMPANY COLONIAL AMERICAN CASUALTY AND SURETY COMPANY FIDELITY AND DEPOSIT COMPANY OF MARYLAND By: Robert D.Murray Vice President aGt/iL 4 Loco\-- By: Dawn E.Brown Secretary State of Maryland County of Baltimore On this 03rd day of March, A.D.2021, before the subscriber,a Notary Public of the State of Maryland,duly commissioned and qualified,Robert D. Murray,Vice President and Dawn E.Brown,Secretary of the Companies,to me personally known to be the individuals and officers described in and who executed the preceding instrument,and acknowledged the execution of same,and being by me duly sworn,deposeth and saith,that he/she is the said officer of the Company aforesaid,and that the seals affixed to the preceding instrument are the Corporate Seals of said Companies,and that the said Corporate Seals and the signature as such officer were duly affixed and subscribed to the said instrument by the authority and direction of the said Corporations. IN TESTIMONY WHEREOF,I have hereunto set my hand and affixed my Official Seal the day and year first above written. Constance A.Dunn,Notary Public ' `r My Commission Expires: �'rrun Ex ires:July 9,2023, — . ;ION% Authenticity of this bond can be confirmed at bondvalidator.zurichna.com or 410-559-8790 -- -- EXTRACT FROM BY-LAWS OF THE COMPANIES "Article V,Section 8,Attorneys-in-Fact. The Chief Executive Officer,the President,or any Executive Vice President or Vice President may, by written instrument under the attested corporate seal, appoint attorneys-in-fact with authority to execute bonds, policies, recognizances, stipulations,undertakings, or other like instruments on behalf of the Company, and may authorize any officer or any such attorney-in-fact to affix the corporate seal thereto;and may with or without cause modify of revoke any such appointment or authority at any time." CERTIFICATE I, the undersigned, Vice President of the ZURICH AMERICAN INSURANCE COMPANY, the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY,and the FIDELITY AND DEPOSIT COMPANY OF MARYLAND,do hereby certify that the foregoing Power of Attorney is still in full force and effect on the date of this certificate;and I do further certify that Article V,Section 8,of the By-Laws of the Companies is still in force. This Power of Attorney and Certificate may be signed by facsimile under and by authority of the following resolution of the Board of Directors of the ZURICH AMERICAN INSURANCE COMPANY at a meeting duly called and held on the 15th day of December 1998. RESOLVED: "That the signature of the President or a Vice President and the attesting signature of a Secretary or an Assistant Secretary and the Seal of the Company may be affixed by facsimile on any Power of Attorney...Any such Power or any certificate thereof bearing such facsimile signature and seal shall be valid and binding on the Company." This Power of Attorney and Certificate may be signed by facsimile under and by authority of the following resolution of the Board of Directors of the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY at a meeting duly called and held on the 5th day of May, 1994,and the following resolution of the Board of Directors of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND at a meeting duly called and held on the 10th day of May,1990. RESOLVED: "That the facsimile or mechanically reproduced seal of the company and facsimile or mechanically reproduced signature of any Vice-President,Secretary,or Assistant Secretary of the Company,whether made heretofore or hereafter,wherever appearing upon a certified copy of any power of attorney issued by the Company,shall be valid and binding upon the Company with the same force and effect as though manually affixed. IN TESTIMONY WHEREOF,I have hereunto subscribed my name and affixed the corporate seals of the said Companies, this 7th day of June , 2022 . Dep:„. SBAL By: Brian M.Hodges Vice President • TO REPORT A CLAIM WITH REGARD TO A SURETY BOND,PLEASE SUBMIT A COMPLETE DESCRIPTION • OF THE CLAIM INCLUDING THE PRINCIPAL ON THE BOND,THE BOND NUMBER,AND YOUR CONTACT .INFORMATION TO: Zurich•Suret",Ciaims 1299 Zurich Way:- _Schaumburg,"IL=6ti196-1056 • ivywv.repot sfclgirr s@zurichna.corn ~ `' 800-b26-4577 Authenticity of this bond can be confirmed at bondvalidator.zurichna.com or 410-559-8790 Additions and Renovation Exhibit B Riverside Public Safety 0-GENERAL GO COVER 1 -CIVIL CO1 EXISTING CONDITIONS & DEMOLITION CO2 SITE PLAN CO3 DIMENSION& GRADING C04 UTILITY C05 PRELIMINARY EROSION CONTROL C06 FINAL RESTORATION PLAN C07 LANDSCAPE PLAN C08 DETAILS 3-DEMOLITION AD1.01 DEMOLITION PLANS -LOWER LEVEL AD1.02 DEMOLITION PLAN-NORTH AD1.03 DEMOLITION PLAN- SOUTH AD1.04 DEMOLITION REFLECTED CEILING PLAN-NORTH AD1.05 DEMOLITION REFLECTED CEILING PLAN-SOUTH AD1.06 DEMOLITION ROOF PLAN-SOUTH AD1.07 DEMOLITION ROOF PLAN-NORTH 4-ARCHITECTURE SP1.01 SITE PLAN A0.01 CODE REVIEW A0.02 UL RATINGS A1.01 LOWER LEVEL-PLAN A1.02 FIRST FLOOR-DIMENSION PLAN-NORTH A1.03 FIRST FLOOR-DIMENSION PLAN- SOUTH A1.04 FIRST FLOOR-NOTE PLAN-NORTH A1.05 FIRST FLOOR-NOTE PLAN- SOUTH Additions and Renovation Riverside Public Safety A 1.06 ROOF PLAN-NORTH A1.07 ROOF PLAN-SOUTH A2.01 ELEVATIONS A2.02 BUILDING SECTIONS A3.01 WALL SECTIONS &DETAILS A3.02 WALL SECTIONS &DETAILS A4.01 INTERIOR ELEVATIONS A4.02 INTERIOR ELEVATIONS A4.03 INTERIOR ELEVATIONS A4.04 INTERIOR ELEVATIONS A4.05 INTERIOR ELEVATIONS A5.01 REFLECTED CEILING PLAN-LOWER LEVEL A5.02 REFLECTED CEILING PLAN-NORTH A5.03 REFLECTED CEILING PLAN-SOUTH A6.01 DOOR SCHEDULE A7.01 FINISH SCHEDULE A7.02 FINISH PLAN NORTH A7.03 FINISH PLAN SOUTH A7.04 FINISH PLAN LOWER LEVEL A7.05 INTERIOR SCHEDULES A7.06 INTERIOR DETAILS A7.07 INTERIOR DETAILS F1.01 FF&E PLAN-NORTH F 1.02 FF&E PLAN-SOUTH 5-STRUCTURAL S0.01 GENERAL DETAILS S0.02 3D VIEWS S0.03 CMU DETAILS S1.01 FOUNDATION PLAN -NORTH Additions and Renovation Riverside Public Safety S1.02 FOUNDATION PLAN-SOUTH S1.03 ROOF FRAMING PLAN-NORTH S1.04 ROOF FRAMING PLAN-SOUTH S2.01 FOUNDATION SECTIONS S2.02 FOUNDATION SECTIONS S3.00 TYPICAL FRAMING SECTIONS S3.01 FRAMING SECTIONS S3.02 FRAMING SECTIONS S4.01 FRAMING ELEVATIONS 6-MECHANICAL,PLUMBING&ELECTRICAL MEP0.01 MECHANICAL/ELECTRICAL COVER SHEET MEP0.02 THROUGH PENETRATION DETAILS MEP1.01 ROOF PLAN M0.01 HVAC DEMOLITION FLOOR PLANS M1.01 HVAC PLAN-FIRST FLOOR- SOUTH M1.02 HVAC FLOOR PLANS M2.01 HVAC CONTROL DIAGRAMS M3.01 MECHANICAL SCHEDULES M4.01 MECHANICAL DETAILS P0.01 PLUMBING DEMOLITION PLANS P1.01 PLUMBING PLAN-FIRST FLOOR-SOUTH P1.02 PLUMBING FLOOR PLANS P2.01 PLUMBING SCHEDULES P3.01 PLUMBING DETAILS E0.01 LIGHTING DEMOLITION FLOOR PLAN E0.02 POWER DEMOLITION FLOOR PLAN E1.01 LIGHTING FLOOR PLANS E1.02 LIGHTING FLOOR PLANS E2.01 POWER FLOOR PLANS Additions and Renovation Riverside Public Safety E2.02 POWER FLOOR PLANS E3.01 ELECTRICAL SCHEDULES/DETAILS E4.01 ELECTRICAL SCHEDULES/DETAILS Additions and Renovation Exhibit C Riverside Public Safety TABLE OF CONTENTS !Division Section Title DIVISION 0—PROCUREMENT AND CONTRACTING REQUIREMENTS 000101 Title Page 000105 Table of Contents 000107 Seals Page 001113 Advertisement for Bids 002113 Instructions to Bidders AIA Document A701 —Instructions to Bidders 002513 Prebid Meetings 002600 Procurement Substitution Procedures 003119 Existing Condition Information 003132 Geotechnical Data Geotechnical Report 003143 Permit Application 004113 Bid Form 004313 Bid Security Forms 004322 Unit Prices Form 004393 Bid Submittal Checklist 005900 Annual Wage Order Annual Wage Order No.28 Platte County 006000 Project Forms AIA Document A101 Agreement Between Owner and Contractor AlA Document A101 insurance and Bonds AIA Document A201 General Conditions 009113 Addenda DIVISION 1-GENERAL REQUIREMENTS 011000 Summary 012200 Unit Prices 012500 Substitution Procedures 012600 Contract Modification Procedures 012900 Payment Procedures 013100 Project Management and Coordination 013200 Construction Progress Documentation 013300 Submittal Procedures 013516 Alteration Project Procedures 014000 Quality Requirements 014200 References 015000 Temporary Facilities and Controls 016000 Product Requirements 017300 Execution 017419 Construction Waste Management and Disposal 017700 Closeout Procedures 017823 Operation and Maintenance Data 017839 Project Record Documents 017900 Demonstration and Training Table of Contents 000105 - 1 Additions and Renovation Riverside Public Safety DIVISION 2—EXISTING CONDITIONS 024119 Selective Demolition DIVISION 3-CONCRETE 033000 Cast-in-Place Concrete DIVISION 4—MASONRY 042200 Concrete Unit Masonry 042613 Masonry Veneer 047200 Cast Stone Masonry DIVISION 5-METALS 051200 Structural Steel Framing 053100 Steel Decking 054000 Cold-Formed Metal Framing 055000 Metal Fabrications 057000 Decorative Metal DIVISION 6—WOOD,PLASTICS AND COMPOSITES 061053 Miscellaneous Rough Carpentry 061600 Sheathing 062013 Exterior Finish Carpentry 064023 Interior Architectural Woodwork 064116 Plastic-Laminate-Clad Architectural Cabinets DIVISION 7-THERMAL AND MOISTURE PROTECTION 072100 Thermal Insulation 072726 Fluid-Applied Membrane Air Barriers 075216 Styrene-Butadiene-Styrene(SBS)Modified Bituminous Membrane Roofing 076200 Sheet Metal Flashing and Trim 079200 Joint Sealants 079219 Acoustical Joint Sealants DIVISION 8-OPENINGS 081113 Hollow Metal Doors and Frames 081213 Hollow Metal Frames 081416 Flush Wood Doors 084113 Aluminum-Framed Entrances and Storefronts 087100 Door Hardware 088000 Glazing 088300 Mirrors 088700 Architectural Window Films DIVISION 9-FINISHES 090190.52 Maintenance Repainting 090561.13 Moisture Vapor Emission Control 092216 Non-Structural Metal Framing 092900 Gypsum Board 093013 Ceramic Tiling 095113 Acoustical Panel Ceilings 095123 Acoustical Tile Ceilings Table of Contents 000105 - 2 Additions and Renovation Riverside Public Safety 096513 Resilient Base and Accessories 096519 Resilient Tile Flooring 096566 Resilient Athletic Flooring 096723 Resinous Flooring 096800 ESD Tile Carpeting 096813 Tile Carpeting 097200 Wall Coverings 099114 Exterior Painting(MPI Standard) 099124 Interior Painting(MPI Standard) 099600 High-Performance Coatings DIVISION 10-SPECIALTIES 101416 Plaques 101419 Dimensional Letter Signage 101423.16 Room-Identification Panel Signage 102113.14 Stainless-Steel Toilet Compartments 102600 Wall and Door Protection 102800 Toilet,Bath,and Laundry Accessories 104413 Fire Protection Cabinets 104416 Fire Extinguishers 105113 Metal Lockers DIVISION 11 -EQUIPMENT 111916 Detention Gun Lockers DIVISION 12-FURNISHINGS 122413 Roller Window Shades 123616 Metal Countertops 123623.13 Plastic-Laminate-Clad Countertops 123661.19 Quartz Agglomerate Countertops—Alternate#2 129200 Interior Planters and Artificial Plants DIVISION 13-SPECIAL CONSTRUCTION No Requirements DIVISION 14-CONVEYING SYSTEMS No Requirements DIVISION 21—FIRE SUPPRESSION 210010 Fire Suppression Provisions 210011 Basic Fire Suppression Materials and Methods 210013 Project Coordination 210505 Fire Suppression Demolition 211300 Existing Fire Protection System Modifications DIVISION 22-PLUMBING 220010 Plumbing Provisions 220011 Basic Plumbing Materials and Methods 220013 Project Coordination 220505 Plumbing Demolition 220523 Valves Table of Contents 000105 -3 Additions and Renovation Riverside Public Safety 220700 Plumbing Insulation 221000 Plumbing Piping 221119 Domestic Water Piping Specialties 221319 Sanitary Waste Piping Specialties 224000 Plumbing Fixtures DIVISION 23—HEATING VENTILATION AND AIR CONDITIONING 230010 Mechanical Provisions 230011 Basic Mechanical Materials and Methods 230013 Project Coordination 230505 Mechanical Demolition 230513 Common Motor Requirements for HVAC Systems 230553 Identification for HVAC Piping and Equipment 230593 System Testing&Balancing 230713 Duct Insulation 230923 Automatic Temperature Controls 233113 Metal Ducts 233300 Air Duct Accessories 233400 HVAC Fans 233616 Variable Air Volume Boxes 233619 Fan Powered Terminal Units 233713 Diffusers,Registers,and Grilles 237416 Rooftop Heating/Cooling Units(3-20 Ton) 237417 Rooftop Heating/Cooling Units(Gas/Electric 20-75 Ton) 238116 Mini-Split Systems 238240 Electric Heaters 238305 Infrared Heaters DIVISION 26-ELECTRICAL 260010 Electrical Provisions 260011 Basic Electrical Materials and Methods 260013 Project Coordination 260505 Electrical Demolition 260519 Wire and Cable 260526 Grounding 260529 Hangers and Supports for Electrical Systems 260533 Raceways and Boxes 260553 Electrical Identification 260923 Lighting Control Devices 260944 Distributed Digital Lighting Control System 262726 Wiring Devices 264113 Lightning Protection System 265000 Lighting 265100 Interior Lighting 265600 Exterior Lighting DIVISION 27—COMMUNICATIONS 270500 Common Work for Communications 270505 Communications Demolition 271100 Communications Equipment Room Fittings 271300 Communications Cabling Table of Contents 000105 -4 Additions and Renovation Riverside Public Safety 275150 Paging System DIVISION 28—ELECTRONIC SAFETY AND SECURITY 280500 Common Work for Electronic Safety&Security 280505 Electronic Safety and Security Demolition 283111 Digital,Addressable Fire-Alarm System 284605 Conductors/Cables for Electronic Safety/Security 284611 Fire Sensors and Detectors 284612 Other Initiating Devices 284613 Other Fire Alarm Devices 284623 Fire Alarm Notification Appliances DIVISION 31 -EARTHWORK Reference Drawings for Requirements DIVISION 32—EXTERIOR IMPROVEMENTS Reference Drawings for Requirements DIVISION 33-UTILITIES Reference Drawings for Requirements Refer to all Addendums for any additions and deletions to the contents of this table regarding specifications and drawings. Table of Contents 000105-5 A�o® CERTIFICATE OF LIABILITY INSURANCE DATE(MMIDD/YYYY) 7/11/2022 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED,subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT IMA, Inc.-Kansas City PHONE NAME: IMA Wichita Team FAX 9393 W. 110th Street (Alc.No.Ext):316-267-9221 (NC,No): Suite 600 ADDRESS: certs@imacorp.com Overland Park KS 66210 INSURER(S)AFFORDINGCOVERAGE NAIC# License#:PC-1210733 INSURER A:Zurich American Insurance Company 16535 INSURED CROSCON-03 INSURER B:Atlantic Specialty Insurance Company 27154 Crossland Construction Company, Inc. PO Box 45 INSURER C:American Guarantee and Liability Insurance 26247 833 S. East Avenue INSURER D:Arch Insurance Company 11150 Columbus KS 66725 INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER:737656884 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR LEFF POLICY EXP T TYPE OF INSURANCE AINSD uwD POLICY NUMBER (MMIDDY/YYYY)I(MM/DIIYYYY) LIMITS A X COMMERCIAL GENERAL LIABILITY GL0859600802 4/30/2022 4/30/2023 EACH OCCURRENCE $5,000,000 CLAIMS-MADE X OCCUR DAMAGE TO RENTED PREMISES(Ea occurrence) $2,000,000 MED EXP(Any one person) $15,000 PERSONAL&ADV INJURY S 5,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE S 10,000,000 POLICY X FM: X LOC PRODUCTS-COMP/OPAGG $10,000,000 OTHER: $ A AUTOMOBILE LIABILITY BAP859615302 4/30/2022 4/30/2023 COMBINED SINGLE LIMIT $5,000,000 (Ea accident) X ANY AUTO BODILY INJURY(Per person) S OWNED SCHEDULED BODILY INJURY(Per accident) $ AUTOS ONLY AUTOS X HIRED X NON-OWNED PROPERTY DAMAGE AUTOS ONLY AUTOS ONLY (Per accident) S C )( UMBRELLA LIAB X OCCUR AUC425515001 4/30/2022 4/30/2023 EACH OCCURRENCE S 10,000,000 EXCESS LIAB CLAIMS-MADE AGGREGATE S 10,000,000 _ DED X RETENTIONS n S A WORKERS COMPENSATION WC859615402 4/30/2022 4/30/2023 X ;MUTE EMPLOYERS'LIABILITY YIN STATUTE ER ANYPROPRIETOR/PARTNER/EXECUTIVE E.L.EACH ACCIDENT $2,000,000 OFFICER/MEMBER EXCLUDED? N N/A -----" (Mandatory in NH) E.L.DISEASE-EA EMPLOYEE S 2,000,000 If yes,describe under DESCRIPTION OF OPERATIONS below • E.L.DISEASE-POLICY LIMIT $2,000,000 B Builders Risk-Reporting 7900130720009 ' 4/30/2022 4/30/2023 Any One Job Site $125,000,000 B Installation Floater-Reporting 7100337760010 4/30/2022 4/30/2023 Any One Job Site $2,500,000 D 2nd Layer Excess Liability UXP300009000 4/30/2022 4/30/2023 Ea Occur$15,000,000 Agg$15,000,000 DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES (ACORD 101,Additional Remarks Schedule,may be attached if more space is required) 3rd Layer Excess Liability:Policy#EXC30000318405,Effective 4/30/2022-4/30/2023,Insurer:Endurance American Insurance Company,NAIC#10641, $10,000,000 Each Occurrence,$10,000,000 Aggregate. 4th Layer Excess Liability:Policy#NHA097780, Effective 4/30/2022-4/30/2023,Insurer:RSUI Indemnity Company,NAIC#22314, $5,000,000 Each Occurrence,$5,000,000 Aggregate. RE:Additions&Renovation Riverside Public Safety-Project No.537-086;CCC Project No.22MO17RWZD.. City of Riverside, Missouri,and WSKF,Inc.are included as Primary Non-Contributory Additional Insured with Completed Operations on the General Liability Policy,if required by written contract or agreement,subject to the policy terms and conditions. • CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE. DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. City of Riverside, Missouri 2950 NW Vivion Road AUTHORIZED REPRESENTATIVE Riverside, MO 64150 _ SAIK \Lk ©1988-2015 ACORD CORPORATION. All rights reserved. ACORD 25(2016/03) The ACORD name and logo are registered marks of ACORD